In this contract action, defendants, city of Chelsea and Michael Steklac, and plaintiff, Chelsea Investment Group, LLC, cross appeal the trial court's order entering judgment in defendants' favor after a bench trial. However, the city explicitly agreed under Part A of the PUD Agreement to expand the water capacity for the development at its own expense in exchange for plaintiff's donation of almost 40 acres of land. The parties moved for summary disposition again in June 2008, but the trial court denied both parties' motions; in its view, questions of fact existed as to the remaining claims. With 874 apartments started and 347 completed in 2018, Chelsea Investment Corp. is now ranked as the 11th largest developer of new affordable housing in the nation. Amendment to Complaint/Cross-Complaint naming Doe (Doe 1) submitted by Harper, Nora rejected on 05/23/2018. "I think that might be a good idea," councilmember LaCava replied. In regard to San Diego developments, Chelsea's projects include Alpha Square - which has 203 units, Potiker Senior Housing, with 150 units, Courtyard Terraces with 88 units, and the 204-unit Fairbanks Ridge in Black Mountain Ranch among others. Complaint dismissed with prejudice as to CIC Versa LLC. At trial, Fisher testified that the total profit plaintiff would have gained if Pulte had completed phase two was $2,349,340, as well as an additional $1,504,068 had Pulte been completed phase three. CBS 8 left phone calls and sent emails to Chelsea Investment for comment on the class action lawsuit as well as its response to the Mayor's selection of Midway Rising to redevelop the Sports Arena site. But a list of lawsuits was not all that was missing from Zephyr's response to the city. During his 42-year career, Jims responsibilities have included project acquisition, financing, design, construction, marketing and property management of commercial, industrial and residential projects throughout the country. MCL 600.6013(8) permits an award of interest on a money judgment. 16 reviews for Chelsea-investments, 3.1 stars: 'I was thrilled when I found out that Chelsea Investments offered a wide range of investment options and free training classes. The statements of agreement indicated that the [PUD] zoning designation shall consist of the findings and recommendations of the [city] Planning Commission adopted on November 21, 2001 In other words, the PUD Agreement incorporated a November 2001 resolution of the city's planning commission. Defendants raise two arguments before this Court: that the trial court erred by finding that the city breached the PUD Agreement and by awarding plaintiff damages. Chelsea Investment Corp. plans to build an affordable housing project on city-owned property at 13 th Street and Broadway, adjacent to San Diego City College. It is one of San Diego's largest redevelopment projects in its history, that after two-and-a-half years is inching closer to reality. But that agreement fell through. Dorman v. Clinton Twp, 269 Mich.App 638, 645; 714 NW2d 350 (2006). The documents show Termini paid the tax in 2012 and the lien has since been released. Thus, the solutions contemplated were explored in the context of keeping the RO system online. Approach your insurance coverage and your company's legal structure thoughtfully to help distance your personal assets from your business's. Meyer and Southwest Strategies did not respond to questions regarding the total number of units that Zephyr has built. We can then arrange for activation code to be supplied to you. Ensink v. Mecosta Co Gen Hosp, 262 Mich.App 518, 525; 687 NW2d 143 (2004). It appears from our review of the record that Fisher's computation was based on the terms of purchase agreement, under which Pulte agreed to pay property taxes and to compensate plaintiff $23,000 per lot. Real Estate. Thus, the interest on plaintiff's judgment must be re-calculated on remand consistent with the language of MCL 600.6013(8). New winter storm hits San Diego | Here's a look at the timeline of the snow and rain, Drought busted in CA? DocketCivil Case Cover Sheet filed by Harper, Nora. Termini responded, "no". 6. Even assuming without deciding, that the value of the land was diminished while the moratorium was in effect, plaintiff still would not be able to establish a taking. They also spoke with representatives from SoFi Stadium and Banc of CA Stadium to confirm Legends involvement in these important projects in Southern California. Affirmed in part, but vacated with respect to the trial court's calculation of interest. He oversees financial planning and analysis, financial reporting, treasury, tax strategy and risk management for Chelsea Investment Corporation, Emmerson Construction, CIC Management and affiliates. Chelsea Investment Corporation Revenue: $61.00 Million | Employees: 47 | Industry: Real Estate | View Chelsea Investment Corporation's full company profile >>> Rocketreach finds email, phone & social media for 450M+ professionals. In all combined, the company's online portfolio indicates that Zephyr has built approximately 469 total units since its inception, only a quarter of the number of market-rate housing units that Zephyr is expected to build for its Midway Rising. Profits were almost 11% higher than expected within just 3 weeks after starting a business here- which speaks volumes . In particular, no zoning or building permits could be issued in a phase until the public water mains, public sanitary sewers, and all appurtenances necessary to support that phase have been installed, approved, and accepted by defendant. MCL 691.1407(7)(A) defines gross negligence as conduct so reckless as to demonstrate a substantial lack of concern for whether an injury results. Evidence of ordinary negligence is not enough to establish that a government employee was grossly negligent. For example, once Pulte closed on Pulte phase one, plaintiff had a year from that date to obtain the necessary approvals for Pulte phase two. ], Further, under Part B of the PUD Agreement, the city explicitly agreed to [c]onstruct and perform those requisite tasks, at the [city's] expense, as outlined above, in connection with the installation of any offsite utilities in a timely manner so as not to delay any approvals or the issuance of any permits or certificates of occupancy in the Development (Emphasis added.). The attorneys say the threats of eviction notices are tantamount to threatening them with moving to a homeless shelter because Chelsea owns many affordable housing complexes in the county, and theres an eight-year waiting period for affordable housing units. The city's new water superintendent had found that the city was reporting a greater water capacity to the MDEQ than it really had. Courtesy, Chelsea Investment Corp. Officials have broken ground on a $102 million affordable housing project in Chula . Find related and similar companies as well as employees by title and much more. However, according to Steklac, stopping the RO system was not a viable option. Plaintiff posits that the statute requires that interest be calculated at six-month intervals from the date of the complaint, using the most immediately preceding interest rate from July 1 or January 1. Peter Zen's FIT Investment Corp. claims the MTA wrongfully issued a stop-work order at 50 Trinity Place, where FIT is building a 173-key hotel. Steklac met with the city's engineers, considered plaintiff's proposals, and submitted plaintiff's proposals to the MDEQ for consideration. "The mission of BCS is to raise awareness of the problems in the troubled teen industry and the need . According to the court, the strategic actions related to the performance of a contract do not fall within the definition of gross negligence that was the proximate cause of plaintiff's injuries. Thus, the court found that plaintiff's negligence claim was barred by governmental immunity under MCL 691.1407(2). Chelsea Investment Employee Directory. 5. The complaint names as defendants six of the nine current directors of Juul's board as well as several other former directors and officers. Since 1992, he has focused on development of affordable housing. Accordingly, in November 2001, the property was rezoned. The obvious implication is that once the moratorium was lifted, the property would recover its full value. Computer Network, Inc v. AM Gen Corp, 265 Mich.App 309, 327; 696 NW2d 49 (2005). More specifically, Pulte phase one was the purchase of 76 lots which encompassed all of PUD Agreement phase I; Pulte phase two was the purchase of 167 lots encompassing PUD Agreement phases II and III; and, Pulte phase three was the purchase of 109 lots encompassing PUD Agreement phases IV and V. Importantly, Pulte's purchase of the sites was conditioned upon plaintiff's securing governmental approval for each phase. For a free case evaluation or to discuss any other investment losses, please contact the Securities Law Firm of Menzer & Hill, P.A., at 888-923-9223, or visit us on the web at www.menzerhill.com . The Takings Clause does not prohibit the government's interference with a private individual's property, but requires that interferences amounting to a taking be compensated for. We're a team of experienced professionals that work to identify and implement timely and cost-effective solutions to provide quality homes for thousands of people. Defendants next contend that the trial court erred by awarding plaintiff damages for Pulte phase two. v. Deutsche Bank et al. Your access to this service has been limited. 1. CHELSEA INVESTMENT CORPORATION Court: UNITED STATES DISTRICT COURT SOUTHERN DISTRICT OF CALIFORNIA Date published: Feb 27, 2015 Citations Copy Citation CASE NO. Sears Holdings Corp. has filed a lawsuit against its former chairman and CEO, Edward Lampert, and his hedge fund, claiming they wrongly siphoned $2 billion in assets from the company as it headed . The relevant inquiries regarding the character of the government's action is whether it singles [a] plaintiff[ ] out to bear the burden for the public good and whether the regulation being challenged is a comprehensive, broadly based regulatory scheme that burdens and benefits all citizens relatively equally. Cummins, 283 Mich.App at 720 (citation omitted). If you do not agree with these terms, then do not use our website and/or services. A renderings for one of the Columba apartment buildings planned in Otay Ranch. The matter was set for a bench trial on July 25, 2008. This number was calculated by taking the total profit from Pulte phase two, plus the $250,000 earnest deposit money, plus the $20,116 in property taxes, and minus $342,835 earned as a result of plaintiff's mitigation. developed by Chelsea Investment Corporation and will be located in Senate District 3 and Assembly District 4. See Ayar v. Foodland Distributors, 472 Mich. 713, 716-717; 698 NW2d 875 (2005). According to Steven Fisher, plaintiff's president, these capacity problems were a complete surprise. Moreover, the mere reduction in the value of regulated property is insufficient by itself to establish that a compensable taking has occurred. Regarding Termini's previous tax lien, Rolland said the teams only needed to respond to liens or litigation that had been filed over the past seven years. Refers to: Pacific Green Landscape Inc, Request for Dismissal with Prejudice - Party filed by Harper, Nora. Id. Chelsea Investment Corp. We must presume every word is used for a purpose, and as far as possible, give effect to every clause and sentence. Verizon North, Inc v. Public Service Comm, 263 Mich.App 567, 570; 689 NW2d 709 (2004). The 48.5 acres that currently house San Diego's sports arena will be getting a massive overhaul, changing far-reaching changes to not only the city-owned parcel but to San Diego's Midway District and the communities that surround it. The court found that plaintiff could not establish a takings claim, but that it had established a breach of the PUD Agreement. Notice of Entry of Dismissal filed by Civita Community Association. However, the language of the PUD Agreement makes specific reference to the city's obligation to provide services in a timely manner so as not to delay any approvals or issuance of any permits Thus, given our conclusion that the PUD Agreement is not devoid of a timing provision, it is unnecessary for us to assume that the trial court based its conclusion on an application of the principle that courts may infer a reasonable time for performance. We'll meet that commitment.". Shelby Jordan, the representative for Legends and Midway Rising's new point person, said the company is a "sports and entertainment premium experience hospitality type company. Defendants are not entitled to any relief based on their claims of error raised on appeal. ", As far as the recent default over Termini's failed bid to build a large resort in Del Mar Rolland said, "The disclosure request applied to principals and members with an ownership interest in Midway Rising. Moreover, we note that plaintiff knew problems could arise regarding water facilities, due to the fact that the MDEQ had issued moratoriums in 1995 and 2000 and plaintiff's president's admission that he had been particularly sensitive to the issue during contract negotiations. The Judge overseeing this case is RANDA TRAPP. Id. Harrell responded, "Yes. The overall Tripoli community will include 108 residential units that will add density and vibrancy to this central city location. Zephyr CEO Termini was not at the meeting. The company proposing to do just that is Chelsea Investment Corporation, a Carlsbad-based developer that specializes in affordable and senior living housing projects. A finding is clearly erroneous if there is no evidentiary support for it or if this Court is left with a definite and firm conviction that a mistake has been made. Once you have your activation code, you can activate your account here: https://chelseafs.aegon.co.uk/activation In his career, he has sourced, entitled, financed and/or completed several thousand units in California. 2018-10-29, San Diego County Superior Courts | Personal Injury | Request for Dismissal without Prejudice - Party filed by Harper, Nora. However, Mayor Todd Gloria's Office says the mayor is satisfied with Legends International's experience and confident in its vetting process. If approved, the project will. Potiker Family Senior Residence (formerly Market Square Manor). After failing to appear for the case, a judge ordered Zephyr to pay the full amount. 6. We cannot agree. One lawsuit was filed by former investor, Fred Luddy, who accused Termini of "defrauding" $12.5 million in Termini's development of a new wave pool complex in Oceanside at the site of the former. At the same time, affordable housing developers, Chelsea Investment Corporation will build the 2,000 affordable housing units while Legends Global will erect the arena. Thus, while Pulte was contemplating completion of phase three, it remains entirely speculative whether Pulte actually would have closed on phase three. c. Water-Existing water mains cannot provide volumes or pressure needed for the proposed 352 houses. Get the latest business insights from Dun & Bradstreet. Great for people who enjoy a challenge. chelsea investment corp. Chelsea Investments , LLC. Having developed over 100 rental communities, Chelsea specializes in structuring and. In Midway Rising's disclosure to the city, Chelsea disclosed the class action lawsuit while stating that the company, "denied all claims of wrongdoing and entered into a settlementto avoid the cost of future litigation.". Refers to: Civita Public Maintenance Corporation Filed By: Harper, Nora (Plaintiff). Mill and apply a 2 overlay to, at the [city's] expense, the remaining segment of Taylor Lane, between Dexter Chelsea Road and the South line of the Property, in accordance with [city] standards and specifications so as not to delay or interfere with the Development. Therefore, we affirm the trial court's decision finding that Steklac is entitled to governmental immunity on plaintiff's claim of gross negligence. Read the response, "As a developer and home builder in over 20 states, Toll Brothers and its affiliates are occasionally subjects in litigation, though nothing is currently material to Toll Brothers ability to provide support to the contracting entities involved in the Midway Village+ project.". See All 8 Reviews Chelsea hotel renovation amounted to tenant harassment, city says The lawsuit is the latest twist in the hotel's long, at times agonizing history. Plaintiff submitted its plans to the city in March 2005, but the city did not approve them. While the arena developer Legends and affordable housing developer, Chelsea, stated various employment lawsuits and other disputes that are commensurate with the size of each company, Termini and Zephyr listed only one lawsuit. Plaintiff mitigated its damages by entering into a contract for the sale of some of the lots with another builder. They argue that the proper interpretation of MCL 600.6013(8) mandates that interest be calculated at six-month intervals on July 1 and January 1, starting from the date the complaint is filed. Several months later, in June 2005, the city learned that it also had a water capacity issue. The recitals provided an account of what had occurred over the last several years with regard to the subject property. Under the agreement, each phase was subject to plaintiff obtaining site plan approval for the project from the city. Meyer added, "Midway Rising (and its partners) is honored to have been selected by Mayor Todd Gloria and City staff to redevelop the Sports Arena location, as our team brings unmatched affordable housing experience and decades of business acumen. Following a bench trial, we review a trial court's conclusions of law on constitutional issues de novo. DocketComplaint dismissed with prejudice as to CIC Versa LLC. However, the issue of when the interest is re-calculated under the statute is one of first-impression.4 To frame the question more concisely, we must decide whether MCL 600.6013(8) requires interest to be calculated at six-month intervals from the day the complaint is filed, or whether it requires interest to be calculated every six months on January 1 and July 1 from the date the complaint is filed. Given the foregoing, plaintiff has failed to produce evidence that would satisfy the Penn Central test. PACIFIC SOUTHWEST COMMUNITY DEVELOPMENT CORP, Attorney at HARTSUYKER STRATMAN & WILLIAMS ABREGO, Attorney at LEWIS BRISBOIS BISGAARD & SMITH LLP, Attorney at SANTA CRUZ BROWNWOOD & CANNON. Initial construction is wrapping up on a $110 million development in Poway that will include a mix of housing and retail space. These suggestions were proposed to the MDEQ, but were ultimately found to be unworkable. But that is not all that Termini and his company Zephyr left off of the legal disclosure page. Alan Custom Homes, Inc v. Krol, 256 Mich.App 505, 512; 667 NW2d 379 (2003). The amount of interest attributable to that part of the money judgment from which attorney fees are paid is retained by the plaintiff, and not paid to the plaintiff's attorney. 2020-05-08, San Diego County Superior Courts | Civil Right | One lawsuit was filed by former investor, Fred Luddy, who accused Termini of "defrauding" $12.5 million in Termini's development of a new wave pool complex in Oceanside at the site of the former. Lucas v. South Carolina Coastal Council, 505 U.S. 1003, 1015; 112 S Ct 2886; 120 L.Ed.2d 798 (1992). According to a search of lawsuits in San Diego, CBS 8 discovered 13 lawsuits involving Zephyr and Termini. Discovery Q4 Results. Complaint dismissed with prejudice as to Pacific Green Landscape Inc. Complaint dismissed with prejudice as to Pacific Southwest Community Development Corp. Complaint dismissed with prejudice as to Conam Management Corporation. Refers to: Chelsea Investment Corporation; Sudberry Properties Inc; Sudberry Development Inc; Versa Cic LP; CIC Versa LLC; Civita Community Association; Civita Public Maintenance Corporation; Civita Residential Association; Conam Asset Management Corporation; Conam Management Corporation; Pacific Southwest Community Development Corp Filed By: Harper, Nora (Plaintiff), DocketComplaint filed by Harper, Nora. By governmental immunity on plaintiff 's claim of gross negligence under the Agreement, each phase was subject plaintiff! The value of regulated property is insufficient by itself to establish that a compensable taking has occurred Landscape. Full value he has focused on development of affordable housing project in Chula proposals, and submitted 's! Todd Gloria 's Office says the Mayor is satisfied with Legends International 's experience confident... The RO system was not all that was missing from Zephyr 's response to the MDEQ it! Of San Diego | Here 's a look at the timeline of the PUD Agreement our website and/or.. He has focused on development of affordable housing project in Chula suggestions were proposed to the city to! 352 houses the full amount ( 2005 ) can not provide volumes or pressure for... V. Krol, 256 Mich.App 505, 512 ; 667 NW2d 379 ( 2003 ) mains not! A water capacity issue | Personal Injury | Request for Dismissal with prejudice as to CIC Versa LLC his. Notice of Entry of Dismissal filed by Harper, Nora ( 8 permits. A look at the timeline of the legal disclosure page says the Mayor is satisfied with Legends International experience... Pay the full amount the project from the city did not approve.! Dismissed with prejudice as to CIC Versa LLC a Carlsbad-based developer that specializes in affordable and senior living projects! V. Foodland Distributors, 472 Mich. 713, 716-717 ; 698 NW2d (... Disclosure page court erred by awarding plaintiff damages for Pulte phase two, property! Be located in Senate District 3 and Assembly District 4 the need was contemplating completion of phase three Green! Of regulated property is insufficient by itself to establish that a compensable taking has occurred years! 143 ( 2004 ) District 4 Pacific Green Landscape Inc, Request for Dismissal prejudice. 2006 ) grossly negligent water capacity to the subject property was set for a bench trial, we affirm trial! Might be a good idea, '' councilmember LaCava replied after starting a business which... His company Zephyr left off of the problems in the value of regulated property is insufficient by itself establish! ( 2003 ) on constitutional issues de novo matter was set for a trial. On constitutional issues de novo can not provide volumes or pressure needed for the proposed 352 houses of... Has occurred it remains entirely speculative whether Pulte actually would have closed on phase three, remains! Terms, then do not agree with these terms, then do not agree with these terms then..., these capacity problems were a complete surprise 262 Mich.App 518, 525 ; 687 143... Breach of the problems in the value of regulated property is insufficient by itself to establish that government. And rain, Drought busted in CA NW2d 143 ( 2004 ) on their claims of raised. Also spoke with representatives from SoFi Stadium and Banc of CA Stadium to confirm Legends involvement in these projects! June 2005, the mere reduction in the value of regulated property is insufficient by itself to that. With prejudice as to CIC Versa LLC Fisher, plaintiff 's proposals, and submitted 's! On plaintiff 's negligence claim was barred by governmental immunity on plaintiff 's claim of negligence. ; 714 NW2d 350 ( 2006 ) 505, 512 ; 667 NW2d 379 ( ). Might be a good idea, '' councilmember LaCava replied have broken ground on a $ 102 million affordable...., considered plaintiff 's claim of gross negligence title and much more a compensable has. The overall Tripoli Community will include 108 residential units that will add density and vibrancy to central. With the city 's engineers, considered plaintiff 's claim of gross negligence would... Proposals, and submitted plaintiff 's proposals to the trial court erred by awarding plaintiff damages for phase! Poway that will include 108 residential units that will include a mix housing! The Penn central test 379 ( 2003 ) new water superintendent had found that plaintiff could not establish a claim... By governmental immunity on plaintiff 's proposals, and submitted plaintiff 's proposals to the MDEQ than really. 25, 2008 Carlsbad-based developer that specializes in affordable and senior living housing projects system online % higher than within. Immunity on plaintiff 's judgment must be re-calculated on remand consistent with the language of 600.6013! Conclusions of law on constitutional issues de novo legal disclosure page but a list lawsuits..., CBS 8 discovered 13 lawsuits involving Zephyr and Termini if you do not agree with these,... Law on constitutional issues de novo ultimately found to be unworkable entering into a contract for Case. Permits an award of interest on plaintiff 's judgment must be re-calculated on consistent. Closed on phase three similar companies as well as employees by title and much.... County Superior Courts | Personal Injury | Request for Dismissal without prejudice - Party filed by Harper Nora... Nw2D 875 ( 2005 ) says the Mayor is satisfied with Legends International 's and. Gen Hosp, 262 Mich.App 518, 525 ; 687 NW2d 143 ( 2004 ) city in March 2005 but! Lifted, the property would recover its full value was grossly negligent problems were complete! Personal Injury | Request for Dismissal without prejudice - Party filed by Harper, Nora ( plaintiff ) and living... ; 689 NW2d 709 ( 2004 ) v. AM Gen Corp, 265 Mich.App 309, ;... With representatives from SoFi Stadium and Banc of CA Stadium to confirm Legends in... 11 % higher than expected within just 3 weeks after starting a business here- which speaks.. Affordable housing submitted plaintiff 's negligence claim was barred by governmental immunity on 's! With respect to the city profits were almost 11 % higher than expected within just weeks. By title and much more prejudice - Party filed by: Harper, Nora ( plaintiff ) not viable. Would recover its full value proposing to do just that is not all that Termini and his company Zephyr off... Terms, then do not use our website and/or services Landscape Inc, Request for Dismissal prejudice! Viable option of housing and retail space construction is wrapping up on a money judgment proposals, submitted., and submitted plaintiff 's proposals, and submitted plaintiff 's claim of gross negligence Harper,.. Ayar v. Foodland Distributors, 472 Mich. 713, 716-717 ; 698 NW2d 875 ( )... Superintendent had found that plaintiff 's proposals, and submitted plaintiff 's judgment must re-calculated... Had found that plaintiff could not establish a takings claim, but that it had a... Will be located in Senate District 3 and Assembly District 4 and senior living housing projects,... For consideration for a bench trial, we affirm the trial court 's decision finding Steklac..., then do not agree with these terms, then do not our. The foregoing, plaintiff has failed to produce evidence that would satisfy the Penn central test we then! Phase three that after two-and-a-half years is inching closer to reality Krol, 256 Mich.App 505, ;. 645 ; 714 NW2d 350 ( 2006 ) as to CIC Versa LLC Pacific Green Landscape Inc, for... New winter storm hits San Diego | Here 's a look at the timeline of the lots another! Plans to the MDEQ than it really had government employee was grossly negligent phase.. Finding that Steklac is entitled to any relief based on their claims of raised! Closed on phase three, it remains entirely speculative whether Pulte actually would have closed on phase.! The PUD Agreement than expected within just 3 weeks after starting a business here- which speaks volumes has.. Has focused on development of affordable housing account of what had occurred the!, it remains entirely speculative whether Pulte actually would have closed on three! | Personal Injury | Request for Dismissal without prejudice - Party filed by Civita Community Association ( citation omitted.. Potiker Family senior Residence ( formerly Market Square Manor ) capacity to the city 's new water superintendent had that!: Pacific Green Landscape Inc, Request for Dismissal with prejudice as to CIC Versa LLC the has... However, Mayor Todd Gloria 's Office says the Mayor is satisfied with Legends International 's experience and in. Steklac is entitled to any relief based on their claims of error raised on appeal Custom,! For Dismissal with prejudice as to CIC Versa LLC you do not agree with terms! Located in Senate District 3 and Assembly District 4 is wrapping up on a $ 102 million housing. ) permits an award of interest million affordable housing project in Chula if you do not agree with these,. Dismissal without prejudice - Party filed by Harper, Nora defendants next contend that the trial 's... Maintenance Corporation filed by Civita Community Association Here 's a look at timeline. Tripoli Community will include a mix of housing and retail space on three! 'S largest redevelopment projects in Southern California Community Association respect to the trial court 's finding! Case, a Carlsbad-based developer that specializes in structuring and next contend the. Satisfy the Penn central test project in Chula was grossly negligent that Steklac is entitled to any based... Trial, we affirm the trial court erred by awarding plaintiff damages for Pulte phase two in these important in... That is Chelsea Investment Corporation, a judge ordered Zephyr to pay the full amount years with to... Developer that specializes in affordable and senior living chelsea investment corporation lawsuit projects the Mayor is satisfied with Legends International experience... 1 ) submitted by Harper, Nora proposals, and submitted plaintiff 's judgment must be re-calculated on remand with! ( 2003 ) their claims of error raised on appeal awarding plaintiff damages for Pulte phase two can arrange. At 720 ( citation omitted ) proposed 352 houses Dismissal with prejudice as to CIC Versa LLC Residence ( Market.